As CLF begins a third year of advocacy on the Northern Pass project, some updates are in order:

The “New Route” Drama

With 2013 only days away, it is looking more and more likely that Northern Pass Transmission LLC (NPT) will not have secured 100% of a “new route” for the project’s northernmost portion by year end, as its public statements have been promising for months. As chronicled in a Boston Globe front-page story published earlier this week (the national daily’s first major story on Northern Pass), landowners are rejecting repeated offers from NPT, and our friends at the Society for the Protection of New Hampshire Forests have secured agreements to conserve key parcels along what appears to NPT’s preferred new path. (According to report in yesterday’s Union Leader, NPT officials are readying some kind of “update” on the project’s progress, which may raise more questions than it answers.)

If NPT fails to make good on its promised “new route,” it will be a singular embarrassment and signal more wasted months of self-inflicted delay. It also will continue NPT’s troubling pattern of misleading investors and peddling falsehoods about the project.

Whatever the success of NPT’s attempt to buy a transmission corridor through New Hampshire’s North Country, Northern Pass overall will remain the same flawed proposal that affected communities and stakeholders have overwhelmingly rejected over the last two years. Susan Arnold of the Appalachian Mountain Club and I penned an op-ed with this message, and it was widely published in New Hampshire newspapers this month. Please take a moment to read the op-ed here.

NU’s False Statements Get Noticed

Over the last month, the Boston Globe, the Concord Monitor, Connecticut newspapers, and NHPR (complete with audio) published stories on Northeast Utilities CEO Tom May’s blatantly false statements about support for Northern Pass. Instead of correcting the comments, NU’s spokesperson compounded Mr. May’s misstatements by insisting, contrary to any possible interpretation of the comments, that Mr. May was speaking about support for the Cape Wind project – a renewable energy proposal backed by a strong public campaign that is co-sponsored by many of the region’s environmental groups. The contrast with Northern Pass couldn’t be starker.

A Broken Permitting Process

The Department of Energy’s permitting process for the Northern Pass project remains tainted by its abdication of responsibility to select an independent and impartial contractor to prepare the crucial environmental impact statement for the project. In a recent letter to Senator Shaheen, DOE repeated its prior position that it sees nothing wrong with the way the current contractor team was selected because NPT’s extraordinary role in the selection process was not unusual. As I explained in October, a precedent of repeating a mistake is no justification. In November, CLF filed a new Freedom of Information Act request to understand the activities of the contractor team, DOE, and NPT during the last year and the extent of NPT’s influence over the direction of the permitting process.

An Underground Alternative Emerges

Meanwhile, we are learning more about a realistic alternative to NPT’s current proposal that could address some community concerns and provide new public revenues. In November, a state legislative commission released an important report highlighting the feasibility of siting underground high-voltage transmission lines in state-owned transportation corridors. The report can be found here (PDF) and followed a lengthy process of collecting testimony and input from dozens of stakeholders, including CLF and a number of other conservation organizations. The report found that underground transmission technologies and corridors are “being used extensively throughout the U.S. and internationally,” “may increase the reliability and security of the electric transmission system,” and “may be technically and financially competitive with other transmission designs and locations.” The commission pointed to other pending transmission projects that incorporate underground technologies sited in state-owned transportation corridors as an indication that this approach “can be technically and financially viable.” (Earlier this week, New York officials recommended approval of one of these projects – the Champlain Hudson Power Express between Québec and New York City, which now includes more than 120 miles of underground high-voltage transmission in active railroad corridors and highways.)

While the state agency officials participating in the commission were reluctant to endorse specific policy proposals in the report (which they saw as outside the commission’s charge), many commission members emphasized the need for a proactive, comprehensive energy plan and a regulatory framework that would help New Hampshire assure that new transmission projects provide meaningful public benefits.

A majority of the commission’s legislator members recommended changes to the state siting process for energy projects, including a requirement that a transmission developer bring forward an underground alternative to any overhead project. It is expected that these recommendations will be among the many legislative proposals to amend the state siting law during the 2013 session of the New Hampshire legislature.

*             *             *

What will 2013 bring for the Northern Pass project and New Hampshire’s energy future? Stay updated by signing up for our newsletter Northern Pass Wire, and be sure to check in with CLF’s Northern Pass Information Center (http://www.clf.org/northern-pass) and all of our latest Northern Pass posts on CLF Scoop. You can also follow me on Twitter, where I often point to recent news articles on Northern Pass.

Yesterday, the U.S. Department of Energy (DOE) and Northern Pass Transmission LLC (NPT) reacted in the media (here and here) to news stories reporting that the federal review of the Northern Pass project has been tainted by DOE’s abdication of critical responsibilities to the project developer and permit applicant, NPT. It is frustrating, but not unexpected given what the document trail revealed, that DOE and NPT don’t see any problems with the permitting process to date.

DOE says that it exercised independent judgment in selecting the contractor team and considered other contractors for the job (while it won’t say which ones or how many, apparently absent a FOIA request, which – if CLF’s last request is an indication – could take as long as a year).

While it is clear DOE signed off on the new team, DOE is ignoring that its actions were wrong because of the undisputedly pervasive role DOE allowed NPT to play –with NPT’s counsel personally recruiting, assembling, and coaching the team, helping the team make its proposal to DOE, making a side agreement (of which DOE apparently has no copy) with the team setting the budget and schedule for the process, and actively helping to draft key DOE documents governing the environmental review.

Giving NPT this role and opportunity for influence is at odds with the core purpose of the legal requirement that any third-party contractor be chosen solely by DOE without meaningful participation by the permit applicant: the selected contractor must have no conflict of interest in favor of the applicant – even a perceived conflict of interest. Like DOE itself, the contractor must be seen by the public as an impartial, independent arbiter of the data, the facts, and the analysis contained in the environmental impact statement of the project. Here, the public can have no confidence that this will be true precisely because NPT was so instrumental in choosing the contractor team. The documents make clear that the contractor team owes its job to NPT. How can the public have any confidence that the team will fulfill its obligations indepedently, with no special treatment or preferences for NPT?

DOE’s other comment – that it is routine for applicants to be involved in selecting contractors – is merely an admission that DOE always handles permitting processes in unacceptably close coordination with developers. “We always do it this way,” is no excuse for illegal and improper conduct.

Indeed, it is telling that DOE has no comment on evidence of actual bias on the part of a senior member of the contractor team who – even before being hired – stated the position (one favored by NPT) that the Champlain-Hudson transmission project is not an alternative to be considered as part of the Northern Pass alternatives review. This evidence means that there is not only a risk of bias with the current contractor team, but that bias already has crept into the process – and on a critically important aspect of the environmental review.

By just adding CLF’s filing (PDF) to the pile of public comments received on the project to date, DOE appears to be following a strategy of bureaucratic defensiveness and imperviousness to public feedback – a strategy that is reflected in one of the most troubling documents CLF obtained, an internal email revealing that one of DOE’s principal priorities is to avoid “setting the precedent of backing down under the weight of public criticism.” If DOE continues on this path, as we say in our filing, “it would be fair for the public to conclude that DOE is not interested in meaningful public involvement and is incapable of reaching a legitimate final decision on the permitting applications that the President and Congress have entrusted it with faithfully reviewing on the nation’s behalf.”

For its part, NPT’s response reflects the absurd allegation that CLF merely is trying to cause delay. To the contrary, our filing with DOE implores the agency to fix the process now, before the permitting process begins again in earnest. Given that there are still several months before NPT says it will restart the process by filing a new northernmost route for the project, DOE has ample opportunity to cure deficiencies.    To be clear, every day of delay that has occurred to date is NPT’s doing – DOE has allowed NPT to drag out the federal environmental review for two years so that it can assemble a new northernmost route, without a definitive end in sight.

NPT also says CLF is trying to “preemptively discredit” the process. Of course, it isn’t CLF’s filing but instead DOE’s and NPT’s own actions, documented in black and white in the 22 exhibits to our filing, that are preemptively discrediting the process.

You can help CLF tell DOE – in only a few clicks – that its actions are unacceptable and that New Hampshire deserves a truly fair review of Northern Pass. Please take action now.

To learn more about this issue, take a moment to review our posts from earlier this week here and here.

For more information about Northern Pass, sign-up for our monthly newsletter Northern Pass Wire, visit CLF’s Northern Pass Information Center (http://www.clf.org/northern-pass), and take a look at our prior Northern Pass posts on CLF Scoop.

DOE Headquarters, Washington, DC (Energy Department photo, credit Quentin Kruger)

A year ago, CLF asked the Department of Energy (DOE) for documents regarding its environmental review of Northern Pass – the major power-line project proposed by Northern Pass Transmission LLC, or “NPT.” We fought for an open, rigorous, and impartial permitting process that would independently scrutinize all elements of the Northern Pass proposal. We wanted to be sure that’s what New Hampshire and the region would be getting from DOE and its new contractor team, which is charged with preparing the ever-crucial environmental impact statement or “EIS” – the document that analyzes the proposed project, all reasonable alternatives, and all related environmental and socio-economic impacts.

On the surface, we saw some blemishes, but it appeared that, despite the potential problems (which we noted in a submission to DOE last October), DOE’s new contractor team would be substantially more objective than the original contractor, which had an obvious conflict of interest due to its dual role (incredibly) working for both DOE to prepare the EIS and for NPT in seeking to obtain state-level approval for the project.

It took nearly a year, but DOE finally sent us a large set of documents – emails, letters, and document drafts. The documents provide the first real window we’ve had into DOE’s handling of the process so far.

What they show is profoundly troubling: abdication by DOE of important non-delegable responsibilities to the permit applicant, NPT; and significant and improper influence over the permitting process by the permit applicant, NPT:

• NPT’s counsel – who was once DOE’s top lawyer and still appears to have extraordinary access and influence at DOE – handpicked the new EIS contractor team, with what appears to be minimal DOE involvement. Counsel for NPT acted as the new contractor team’s agent, recruiting the team, pulling together its submission of qualifications and a work plan proposal to DOE, and organizing a face-to-face meeting between DOE, NPT, and the team. It appears DOE conducted no real search of its own, in violation of governing regulations requiring that EIS contractors be chosen “solely” by DOE.
• A senior member of the new contractor team has already demonstrated that she is biased in favor of a narrow, NPT-preferred alternatives analysis. In an email included in the documents obtained by CLF, one of the new contractors opined that the underground Champlain Hudson Power Express project connecting Canada and New York City will not be considered an alternative to Northern Pass in the EIS. This is precisely the position expressed just one month earlier by NPT in its objection to CLF’s and others’ request for a regional energy study, which was based in part on DOE’s need to evaluate Northern Pass and Champlain Hudson together. The email was, ironically, intended to show that email’s author lacks a conflict of interest in working as an EIS consultant on the Northern Pass project and as a DOE consultant on the Champlain Hudson project.
• DOE allowed NPT to design the arrangement among DOE, NPT, and the contractor team, which was memorialized in a Memorandum of Understanding that, we’ve learned, DOE asked NPT to draft. It appears that DOE doesn’t even have a copy of the key agreement between NPT and the contractor team establishing the budget and schedule for the EIS.

Unfortunately, this pattern of NPT’s influence over the process is not unique to selecting and managing the project’s EIS contractors:

• DOE apparently reviewed and okayed NPT’s deeply incomplete permit application before it was even filed.
• DOE asked NPT’s counsel to write up the “purpose and need for agency action,” a crucial DOE determination that will help shape the scope of the EIS, including what alternatives to the current Northern Pass proposal should be studied. NPT’s draft was virtually identical to the version that then appeared in last year’s Federal Register notice announcing that DOE would prepare an EIS and kicking off the scoping process. In our scoping comments, CLF identified DOE’s “purpose and need” statement as illegally narrow.
• NPT and DOE have had private discussions, outside the public eye, about pending requests by stakeholders to improve DOE’s process. In the case of CLF’s and others’ request for a regional study of our energy needs, a request that became all the more important in the aftermath of the announcement of the Northeast Energy Link project last July, NPT’s counsel went so far as to give DOE talking points and supporting legal citations explaining why granting the request was “not warranted.” DOE’s decision on the request? As NPT would prefer, DOE hasn’t commissioned any regional study or EIS.

What should happen next? Yesterday, CLF filed extensive comments with DOE (1 mb PDF linked here, 10 MB .zip archive of exhibits here), laying out the evidence and requesting major changes in DOE’s environmental review of Northern Pass:

• First, DOE’s new contractor team has a clear conflict of interest, in violation of governing regulations that prohibit the use of contractors with “any conflict of interest.” The team apparently owes its new contractor job – and potentially hundreds of thousands of dollars in consultant fees – to NPT. To ensure the objectivity and integrity of the permitting process, the new contractor team needs to be replaced by a new contractor or qualified DOE team with no conflicts of interest, and without NPT’s involvement.
• Second, and more fundamentally, DOE needs to change course – now. New Hampshire deserves a fair, impartial, and rigorous review of Northern Pass. NPT, as the permit applicant, predictably would prefer an easy path to approval. It’s DOE’s legal obligation to control the process, promote meaningful public involvement, and safeguard its decision-making from bias and undue influence. In light of NPT’s failure to piece together a northernmost route, DOE has ample time to start again, with a more open and objective approach that would help to rebuild the public’s confidence in this important permitting process.

UPDATE: Help us tell DOE to fix the process by replacing the contractor team and instituting the fair, legally sound process that New Hampshire deserves. It only takes a few clicks. Take action now here.

For more information about Northern Pass, sign-up for our monthly newsletter Northern Pass Wire, visit CLF’s Northern Pass Information Center (http://www.clf.org/northern-pass), and take a look at our prior Northern Pass posts on CLF Scoop.

photo credit: flickr/brianjmatis

This week, the New England Power Generators Association (the trade group for most of the region’s power plant companies, also known as NEPGA) released a new study analyzing the potential effect of the Northern Pass project on New England’s energy market – the first independent study addressing this issue. More than two years after the deeply flawed energy study that Northern Pass’s developer commissioned and has cited unrelentingly since, NEPGA’s study is an important, credible contribution to the public discussion surrounding the Northern Pass project.

The new study’s conclusion: the supposed energy benefits of the project – that it will lower the region’s energy costs and diversify the region’s power supply – won’t materialize. The study also shows that the economic merits of the current proposal are much weaker today than they were when the proposal was formulated two years ago, due to reductions in the cost of natural gas.

You can read NEPGA’s press release about the study (PDF) here and the full study (PDF) here. You’ll find press coverage of the study in the Union Leader here, in the Concord Monitor here, on WMUR-TV here, and on New Hampshire Public Radio here.

A few key takeaways:

• The study’s finding that natural gas prices have declined is not news to Hydro-Québec or to Northern Pass’s developer, which is trumpeting new domestic natural gas supplies as a “game-changer.” What this means, in practical terms, is that the project will not put much downward pressure on the already-low regional market price of power. That’s a problem for Northern Pass: reducing regional energy costs is at the heart of the Northern Pass sales pitch. (As we’ve pointed out before, this “benefit” in fact perversely would put upward pressure on – rather than lower – the rates that most New Hampshire consumers pay.)
• With the economics of the project so tenuous, there is a clear risk that the proponents will seek to qualify Northern Pass power for the benefits afforded to new renewable energy sources under state clean energy laws, a legal change that would unfairly undermine the market for renewable energy development in New England. (The risk that hydropower imports will need subsidies to cover new transmission costs has also recently been cited by critics of the Champlain Hudson Power Express project in New York.) If it’s true, as proponents insist, that Northern Pass doesn’t need subsidies, New England should accept nothing less than a binding legal commitment from Hydro-Québec and Northern Pass’s developer not to seek or accept them.
• NEPGA’s study suggests that Northern Pass would shift Québec hydropower exports from New York and Ontario to New England. This effect may completely offset the supposed carbon emissions reductions from Northern Pass (which are inherently dubious for other reasons) because it is extremely likely that New York or Ontario would ramp up natural gas power plants to make up any deficit. In this regard, the study shows yet again that a rigorous big-picture regional analysis – of the kind that could be provided in the comprehensive regional assessment of our energy needs and the role, if any, for more Canadian imports that CLF and others have sought and Northern Pass’s developer has opposed – is essential to making a well-informed decision on a proposal like Northern Pass.
• The developer’s hair-trigger response – to question the credibility of the sponsors of the study and not the study’s actual findings, a classic Bulverism – speaks volumes. At every turn, the developer has refused to acknowledge or address the problems with its current proposal, even in the face of unequivocal facts that debunk the supposed benefits. Sadly, we can expect the potential rollout of the “new route” for a piece of the project later this summer to follow a similar script.

Above all, NEPGA’s new study underscores that that no one should rely on the stale, incomplete, and misleading information that Northern Pass’s developer is using to sell the project to the public and to government agencies. We need a much deeper, clear-eyed understanding of what Northern Pass would mean for the region’s energy consumers, New Hampshire communities, and the environment on both sides of the border.

For more information about Northern Pass, sign-up for our monthly newsletter Northern Pass Wire, visit CLF’s Northern Pass Information Center (http://www.clf.org/northern-pass), and take a look at our prior Northern Pass posts on CLF Scoop.

This summer, New Hampshire is bracing for news of the Northern Pass project’s future and its “new route.”

It’s now been nearly a year since the federal permitting process for the Northern Pass project was put on indefinite hold. North of Groveton, New Hampshire, the developer – Northern Pass Transmission LLC (NPT) – is still working behind tightly closed doors to string together a new section of the project route, where there are no existing transmission corridors, by paying landowners substantial sums for property – in many cases, well above market value.

Earlier this month, the chief operating officer of NPT’s parent company, Northeast Utilities, told investors:

Where we are right now is in procuring the last 40 miles of the right-of-way, and I can tell you we are making very, very strong progress in lining up the right of way. I think we’re on track for the middle of the year, approximately August timeframe to have the right-of-way secured and then to be prepared to file with the [U.S. Department of Energy] the route….

NPT’s apparent plan (assuming it really can overcome the considerable obstacles to a new route):

• Declare that it “heard the objections” to the original route (a posture it previewed last April when it agreed to look for new routes)
• Announce a new NPT-controlled route having the “support of property owners” (as it no longer has resort to eminent domain)
• Marginalize those with legitimate objections as “special interests” and
• Seek a speedy, narrow review of the proposal from federal and state regulators (after itself having put the permit process on hold for a year).

Not so fast. Before the news arrives (if it does), it’s worth remembering that whatever new lines the developer manages to draw on the map do nothing to change the project’s DNA or to demonstrate that the project will benefit New Hampshire. A brief review is in order:

Where are the benefits for New Hampshire?

Through  costly marketing efforts, NPT has been trying to sell New Hampshire on the tremendous economic and environmental benefits of Northern Pass. But the supposed benefits just don’t hold up to scrutiny:

• Reduced emissions from “clean power”?

In terms of greenhouse gas emissions, CLF’s report on the most recent science demonstrated that new hydropower projects to supply power for Northern Pass are much worse for the climate than NPT’s false advertising claims have led the region to believe and are not meaningfully better than natural gas power plants (the power NPT predicts that Northern Pass would replace) in the early years after reservoirs are developed. As a result, contrary to mistaken but widely disseminated assumptions, importing hydropower from Canada is not a short-term solution that will reduce New England’s or New Hampshire’s carbon emissions. Indeed, the current proposal would have the perverse effect of protecting – rather than hastening the transition away from – PSNH’s low-performing, high-emitting power plants, which are New Hampshire’s largest source of greenhouse gas emissions. (Despite marketing the project based on its “clean” source of the power, NPT also refuses to acknowledge the relevance or importance of the troubling damage to ecosystems and communities that large-scale hydropower causes in Canada.)

• Lower electric rates?

Those who would live with the new transmission lines, customers of NPT affiliate PSNH, are the least likely to benefit. Despite nearly two years of promises that PSNH would announce a plan to purchase Hydro-Québec hydropower for New Hampshire residents, there is still no agreement to do so. Any modest effects on the region’s wholesale electricity rates (which NPT’s consultant predicted based on outdated economic assumptions about energy costs) don’t translate into lower rates for PSNH customers (who instead are stuck paying the bill for PSNH’s inefficient and dirty power plants). In fact, if Northern Pass succeeds in lowering wholesale rates, it will likely worsen PSNH’s death spiral of increasing rates and fewer customers, leaving those residents and small businesses still getting power from PSNH with higher bills.

• Growing New Hampshire’s clean energy economy and jobs?

There is a substantial risk that Northern Pass would swamp the market for renewable energy projects in New England, especially if state laws are amended to qualify Hydro-Québec power as “renewable.” Furthermore, the project’s high voltage direct current technology means that its massive investment in transmission capacity will wholly bypass the potentially fertile ground for renewable energy development in northern New England. Whatever the short-term construction jobs required (and NPT’s estimates are disputed), the current Northern Pass proposal may diminish the prospects for New Hampshire’s clean energy economy, including needed permanent jobs in the renewable and energy efficiency sectors.

No regional plan addressing new imports

Québec continues to implement its ambitious plan to develop more wild Boreal rivers into a new generation of massive hydropower projects, which will increase its export capabilities. This January, Hydro-Québec commissioned the final turbine at its latest hydropower facility (Eastmain 1-A) and will commission other turbines (at Sarcelle) as part of the same overall project later this year. Construction at the $8 billion Romaine River hydropower project (the subject of the film Seeking the Current) has begun and is ongoing, with the first unit expected to come online in 2014. Northeast Utilities has affirmed that Northern Pass will tap the power from these new projects. Meanwhile, Northern Pass competitors are moving forward with new transmission projects in eastern New England and in New York, among others:

Northern Pass and competitor transmission projects (source: ISO-NE)

More than a year ago, CLF and others urged the Department of Energy to weigh the region’s energy needs and develop a strategic regional plan that would determine a well-informed role for new Canadian hydropower imports in the northeastern United States’ energy future – before moving forward with the permitting process for Northern Pass. NPT’s only response was that responsible planning – encompassing the other pending transmission projects and a full consideration of the reasonable alternatives – would unacceptably delay its project – a truly ironic claim given NPT’s own, unforced, ongoing delay. More incredibly, the Department of Energy has so far sided with NPT, without explaining why.

So as Québec builds more dams and NPT buys up land, our region has no plan of its own. With no framework to understand the nature and extent of the appropriate role for Canadian hydropower, it is difficult if not impossible to make a sound, well-informed decision on whether Northern Pass – or projects like it – should proceed.

Community and grassroots reaction throughout New Hampshire

Since Northern Pass was announced in 2010, the project has inspired a broad-based and spirited movement of people throughout New Hampshire to oppose the current proposal. Last spring, there were massive turnouts at the Department of Energy’s public hearings on the project, with literally thousands attending and providing written and verbal comments both questioning the merits of the current proposal and urging a thorough environmental review. And earlier this year, a coalition of citizens and organizations of many political stripes succeeded in persuading New Hampshire’s legislature to enact a bill preventing projects like Northern Pass from using eminent domain. In another effort, more than 1,500 donors contributed total of $850,000 to enable the Society for the Protection of New Hampshire Forests to preserve the treasured New Hampshire landscape surrounding the historic Balsams resort, including a parcel that NPT had sought to purchase as part of Northern Pass’s transmission corridor. To date, town meeting voters in 32 local communities have passed resolutions and ordinances against the current proposal. Critically, most of these communities are located along the NPT’s “preferred route” that follows PSNH ‘s existing transmission corridor, south of any “new route” that NPT may announce.

NPT’s refusal to consider routing and technological alternatives

At every turn, NPT has rejected calls for in-depth consideration of potential alternatives to its current proposal, including use of an existing high-voltage transmission corridor that extends from Canada, through Vermont and western New Hampshire, to Massachusetts; burying transmission lines in transportation corridors, as is proposed in the New York and eastern New England projects mentioned above; or adding capacity to that same New York project, consistent with that project’s original proposal (it has since been scaled back). Indeed, Northern Pass’s response to the public’s opposition to the project was to “withdraw support” for alternative routes and double down on its “preferred route.” While this stance may be in the economic interest of NPT and PSNH, it’s grossly at odds with a fair, well-informed permitting process that would vindicate the public’s interest in a solution with minimal environmental and community impacts.

If and when NPT comes back from its year of buying up North Country land and relaunches its effort to secure approval of the Northern Pass project, with the only change to the proposal consisting of a new line on the map north of Groveton, there should be no mistake: the fundamental flaws in the current proposal remain. Likewise, whatever NPT’s “preferred route,” CLF remains as committed as ever to securing a comprehensive and rigorous permitting process that identifies superior alternatives and a final outcome that moves us toward – and not away from – a clean energy future for New Hampshire and the region.

For more information about Northern Pass, sign-up for our monthly newsletter Northern Pass Wire, visit CLF’s Northern Pass Information Center (http://www.clf.org/northern-pass), and take a look at our prior Northern Pass posts on CLF Scoop.

With Northern Pass and other new transmission projects on the horizon, CLF and other leading New Hampshire environmental organizations are presenting a special free webinar on what it really means for New England to import more hydroelectric power from Canada.

The webinar will be next Friday, March 9, 2012, 2:30 to 4pm EST. Click here to register. All you’ll need is a computer and an Internet connection. Please join us, and spread the word to friends, family, and colleagues. The webinar is sponsored by CLF and our friends at the Appalachian Mountain Club, Conservation New Hampshire, The Nature Conservancy in New Hampshire, and the Society for the Protection of New Hampshire Forests (SPNHF). 

A scene along the Romaine River from Seeking the Current (copyright Chercher le Courant)

The idea is to provide an accessible summary of the environmental and energy implications of imports, including the often-overlooked impacts of the new hydropower developments in Canada that will supply the power. One of the key questions is what new imports will really mean for the climate, and I’ll explain the findings of a recent report commissioned by CLF on the greenhouse gas emissions of hydropower. As we’ve often pointed out, whether and how to import more hydropower from Canada is a critical issue for the entire region’s energy future. And it’s not just about New Hampshire and Northern Pass — just last week, the developer of the Champlain Hudson project in New York announced that it is moving forward with a revised proposal for an underwater and underground transmisssion line between Canada and New York City that will have the support of state officials, municipal governments, and environmental groups.

During the webinar, you’ll hear from me, and also from Tom Irwin, CLF Vice-President and CLF-NH Director; Ken Kimball, AMC Director of Research; and Will Abbott, SPNHF Vice President for Policy and Land Management.

The webinar will feature a special guest appearance by Québecois filmmaker Nicolas Boisclair, who will be in New Hampshire this month for a series of screenings of his documentary film, Seeking the Current, which shines an unsparing light on Hydro-Québec and its ongoing $8 billion hydropower project on the Romaine River. We’ve put all the details on the screenings (and the webinar too) at this link.

For more information about Northern Pass, sign-up for our monthly newsletter Northern Pass Wire, visit CLF’s Northern Pass Information Center (http://www.clf.org/northern-pass), and take a look at our prior Northern Pass posts on CLF Scoop.